Terms and Conditions

Effective Date: June 2025

Terra General Contractor LLC – El Paso, Texas

Welcome to the website of Terra General Contractor LLC. By accessing or using our website and services, you agree to comply with and be bound by the following Terms and Conditions. Please read them carefully.

1. Services Provided

Terra General Contractor LLC provides general contracting services in El Paso, Texas, including electrical, plumbing, and framing for residential and commercial projects. All services are subject to written agreements and project-specific contracts.

2. Use of Website

• You agree to use this website only for lawful purposes.

• You may not use this website to engage in fraudulent activities, distribute harmful software, or attempt unauthorized access.

• Content on this website is provided for informational purposes only and may change without notice.

3. Estimates and Agreements

• Estimates provided through this website or via phone/email are preliminary and subject to change after inspection and review.

• Final project details, pricing, and timelines will be outlined in a signed service agreement.

• Terra General Contractor LLC reserves the right to decline services if conditions fall outside our scope or licensing.

4. Payment Terms

• Payment terms and schedules will be specified in each project agreement.

• Late payments may be subject to additional fees as outlined in the service contract.

• Failure to pay may result in suspension of work until the account is current.

5. Licensing and Insurance

Terra General Contractor LLC is a licensed and insured contractor in the State of Texas. Copies of licensing and insurance documents are available upon request.

6. Limitation of Liability

• While we strive for quality workmanship, Terra General Contractor LLC is not liable for damages arising from misuse, neglect, or third-party interference after project completion.

• We are not responsible for delays caused by factors beyond our control, including weather, supply shortages, or subcontractor performance.

7. Intellectual Property

• All content on this website, including text, images, and logos, is the property of Terra General Contractor LLC unless otherwise noted.

• You may not copy, distribute, or reproduce our website content without prior written consent.

8. Third-Party Links

Our website may include links to third-party sites for additional resources. We are not responsible for the content, privacy practices, or accuracy of information on external websites.

9. Privacy Policy

Use of this website is also governed by our Privacy Policy, which explains how we collect, use, and protect your personal information.

10. Changes to Terms

Terra General Contractor LLC reserves the right to update or modify these Terms and Conditions at any time. Updates will be posted on this page with the revised effective date.

11. Governing Law

These Terms and Conditions are governed by the laws of the State of Texas. Any disputes arising from use of this website or our services shall be resolved in the courts located in El Paso County, Texas.

12. Contact Us

If you have any questions about these Terms and Conditions, please contact us:

Terra General Contractor LLC

El Paso, Texas

📞 Phone: 915.274.8672

📧 Email: info@deeppink-salmon-998990.hostingersite.com